On February 24, 2016, the Supreme Court of Ohio handed down a merit decision in Boone Coleman Constr., Inc. v. Piketon, 2016-Ohio-628. In a fractured 6-1 opinion authored by Chief Justice O’Connor, the court upheld a contractual liquidated-damages provision in a public road construction contract. Only Justice O’Neill fully concurred in the court’s opinion.
Penalty
What’s On Their Minds: Liquidated Damages or Penalty in Public Construction Contract? Boone Coleman Construction Co., Inc. v. Village of Piketon, Ohio.
By Marianna Bettman on
Update: On February 24, 2016, the Supreme Court of Ohio handed down a merit decision in this case. Read the analysis here.
“Is this a big problem in the construction area? I don’t see a whole host of amici here coming to your side of the table. I’d say the construction industry, especially those that…
Oral Argument Preview: Liquidated Damages or Penalty in Public Construction Contract? Boone Coleman Construction Co., Inc. v. Village of Piketon, Ohio.
By Marianna Bettman on
Update: On February 24, 2016, the Supreme Court of Ohio handed down a merit decision in this case. Read the analysis here.
Read the analysis of the oral argument here.
On June 9, 2015, the Supreme Court of Ohio will hear oral argument in the case of Boone Coleman Construction Co., Inc. v. The Village…